Recovering the commercial damages incurred during the construction of a US$723 million high-voltage power line.
A new 500-kilovolt transmission line was built to deliver reliable power to major populations centers in a Canadian province. It carries electricity from transmission points along two rivers to more than 3.2 million people.
A utility corporation owned by the government and citizens of the province was awarded the design-build contract in 2011. Construction got underway on the largest expansion in three decades of the state’s transmission system the following year.
The transmission line was completed almost a year late in 2015, following delays caused by a range of factors including scope changes, design and construction challenges, and conditions along the line’s route. The new line was built through some of Canada’s most challenging and diverse terrain, crossing mountains, major rivers, grasslands and highways. It also traverses public and private lands.
Brief
The main contractor retained HKA to provide delay and disruption analysis and forensic accounting analysis associated with a US$310 million claim on the project.
What we did
We assembled an expert team comprising specialists in the following areas:
- Schedule analysis and support
- Forensic delay analysis
- Disruption / loss of productivity quantum analysis
- Forensic accounting
We also provided expert witness testimony during arbitration, along with services for the arbitration hearing and post-brief support.
Outcomes
Our comprehensive and detailed analysis provided the basis for our client’s successful claim and the recovery of the majority of its incurred costs.
The arbitrator – in a decision released in March 2018 – found that changes made by the utility corporation to a portion of the line had delayed the contractor’s work. Also, access problems involving private land and archaeological sites disrupted its construction schedule, causing a loss of productivity and additional costs for which the utility was responsible under the contract.
Interest was also payable on some of these award amounts, taking the total recovered in commercial damages to approximately US$135 million.
![](https://cdn.hka.com/wp-content/uploads/2019/08/shutterstock_1112383511-480x340.jpg)
"Our comprehensive and detailed analysis provided the basis for our client’s successful claim and the recovery of the majority of its incurred costs."
Paul Pocalyko, Partner, HKA
-
ClientConfidential
-
ValueUS$723 million
-
ServicesCommercial Damages and Valuation, Delay and Disruption Analysis
-
SectorsConstruction and Engineering, Power and Utilities
RELATED PROJECTS
RELATED PROJECTS
![](https://cdn.hka.com/wp-content/uploads/2020/01/faris-mohammed-uG5_ERHN040-unsplash-280x210.jpg)
Independent Quantum Expert Opinion of Highway Maintenance Contract
Europe
![](https://cdn.hka.com/wp-content/uploads/2020/10/UNSW5-280x210.jpg)
UNSW Capital Projects Sustainability Framework
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/12/shutterstock_1289920885-280x210.jpeg)
Subsea Cable Installation & Trenching Operations
Asia
![](https://cdn.hka.com/wp-content/uploads/2022/11/shutterstock_191351435-280x210.jpg)
Coal-fired power plant
Asia
![](https://cdn.hka.com/wp-content/uploads/2019/06/pexels-pixabay-162646-280x210.jpeg)
Missouri Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/matt-seymour-NcmOysOF_Mw-unsplash-280x210.jpg)
Independent Commercial, Cost & Risk Review of Road Development
Europe
![](https://cdn.hka.com/wp-content/uploads/2020/11/yucar-fotografik-cfR-V1QuEKw-unsplash-280x210.jpg)
Sydney Water, Partnering for Success (P4S)
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/12/shutterstock_1372606610-280x210.jpeg)
Subsea Interconnector Cable Failure
Europe
![](https://cdn.hka.com/wp-content/uploads/2022/11/shutterstock_576018130-280x210.jpg)
Coal-fired power plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2019/07/pexels-johannes-plenio-4460676-280x210.jpeg)
Spent Nuclear Fuel Verdicts & Settlements
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/shutterstock_739242352-280x210.jpeg)
Independent Quantum Expert Review of Maintenance Contract
Europe
![](https://cdn.hka.com/wp-content/uploads/2021/01/AdobeStock_261723143_Melbourne_web-e1707447623872-280x210.jpg)
Melbourne Airport Rail
Oceania
![](https://cdn.hka.com/wp-content/uploads/2022/01/FACD-280x210.jpg)
Energy and Telecom Cable Manufacturer
Americas & Asia
![](https://cdn.hka.com/wp-content/uploads/2022/11/shutterstock_2012903819-280x210.jpg)
Water desalination plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2019/07/shutterstock_609628034-280x210.jpg)
Longview Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/shutterstock_64845340-1-280x210.jpg)
Major Light Rail Transit
Americas
![](https://cdn.hka.com/wp-content/uploads/2021/07/shutterstock_1315203980-3-280x210.jpg)
Liquefied Natural Gas (LNG) Project Australia
Oceania
![](https://cdn.hka.com/wp-content/uploads/2022/07/shutterstock_526595785-280x210.jpeg)
Clean Fuels Project
Middle East
![](https://cdn.hka.com/wp-content/uploads/2021/06/shutterstock_539854030-280x210.jpeg)
Offshore refinery contractor performance review
Asia
![](https://cdn.hka.com/wp-content/uploads/2019/07/pexels-pixabay-263402-280x210.jpeg)
University of North Carolina Hospitals
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/02/shutterstock_701032348-1-280x210.jpg)
Two New Venues
Middle East
![](https://cdn.hka.com/wp-content/uploads/2021/08/WhatsApp-Image-2021-08-08-at-10.38.13-AM-280x210.jpeg)
Residential Development
Middle East
![](https://cdn.hka.com/wp-content/uploads/2022/07/shutterstock_1700360854-280x210.jpg)
Nuclear Power Plant Decommissioning
Americas
![](https://cdn.hka.com/wp-content/uploads/2023/11/Rozelle-interchange-280x210.jpg)
WestConnex Rozelle Interchange
Oceania
![](https://cdn.hka.com/wp-content/uploads/2019/07/shutterstock_1931109776-280x210.jpg)
Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/02/pexels-thirdman-5327915-280x210.jpeg)
A Major Teaching & Research Hospital
Europe
![](https://cdn.hka.com/wp-content/uploads/2021/08/shutterstock_671935024-scaled-1-280x210.jpg)
Natural Gas-Fired Power Plant
Asia
![](https://cdn.hka.com/wp-content/uploads/2022/06/Generic-Industrial-Manufacturing-33-280x210.jpg)
Global chemicals manufacturer
Americas & Europe
![](https://cdn.hka.com/wp-content/uploads/2019/06/zbynek-burival-517983-unsplash-280x210.jpg)
South American Oil Refinery
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/04/shutterstock_1898870809.jpg)
Nuclear Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2021/06/shutterstock_93575686-280x210.jpeg)
Industrial Manufacturing Facility
Europe
![](https://cdn.hka.com/wp-content/uploads/2022/09/chris-dack-6H9XK16F3wU-unsplash-280x210.jpeg)
Business Park, Surrey
Europe
![](https://cdn.hka.com/wp-content/uploads/2019/07/shutterstock_137593487-280x210.jpg)
Major Nuclear Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/10/Picture2-280x210.jpg)
New School Campus, Ultimo Primary School
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/12/shutterstock_1085652248-280x210.jpeg)
Subsea Power Cable Failure
Asia
![](https://cdn.hka.com/wp-content/uploads/2022/09/pexels-julia-volk-5201944-280x210.jpeg)
Highway Rock Cuttings
Middle East
![](https://cdn.hka.com/wp-content/uploads/2019/01/pexels-trinity-kubassek-230620-280x210.jpg)
Share our Space Program
Oceania
![Pioneering Spirit Allseas Oil and Gas Offshore](https://cdn.hka.com/wp-content/uploads/2019/01/allseas-pioneering-spirit-280x210.jpg)
Allseas & Pioneering Spirit
Europe
![Sydney Water Lower South Creek Treatment Program Australia Tap](https://cdn.hka.com/wp-content/uploads/2019/01/bathroom-black-and-white-blur-615326-280x210.jpg)
Lower South Creek Treatment Program
Oceania
![Hume Housing | Infrastructure | Expertise | HKA](https://cdn.hka.com/wp-content/uploads/2018/11/Hume-Housing-280x210.png)
Hume Community Housing
Oceania
![](https://cdn.hka.com/wp-content/uploads/2018/09/joey-kyber-Pihl8kTtX-s-unsplash-280x210.jpeg)
Infrastructure Investment Assurance Framework
Oceania
![](https://cdn.hka.com/wp-content/uploads/2018/09/bigstock-Two-electricians-securing-powe-26134499-280x210.jpg)
Electricity Network Improvement
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/06/shutterstock_535814989-280x210.jpg)
High Speed 2 (HS2) Project
Europe
![Sydney Major Transport | Infrastructure | Expertise | HKA](https://cdn.hka.com/wp-content/uploads/2018/10/Sydney-Major-Projects-e1554899277213-280x210.jpeg)
Major Transport Projects Review
Oceania
![City metro Australia Newcastle Project Advisory](https://cdn.hka.com/wp-content/uploads/2018/08/Newcastle_City-Metro-Rail-motion-blur-280x210.jpg)
Urban Transformation & Transport Programme
Oceania
![](https://cdn.hka.com/wp-content/uploads/2018/08/EssentialEnergy-280x210.jpg)
Strategic Procurement & Programme Management Improvement
Oceania
![](https://cdn.hka.com/wp-content/uploads/2017/03/AdobeStock_378243029-280x210.jpeg)
Sydney Metro
Oceania
![Ultimo Pop Up School Australia Sydney](https://cdn.hka.com/wp-content/uploads/2018/07/Ultimo-Pop-Up-School-Australia-280x210.jpg)
Temporary School at Ultimo Primary School
Oceania
![](https://cdn.hka.com/wp-content/uploads/2020/11/Construction-image-scaled-e1635262262716-280x210.jpg)
Gerald Desmond Bridge
Americas
![](https://cdn.hka.com/wp-content/uploads/2021/03/shutterstock_1140608543-280x210.jpg)
Office and Retail Landmark
Americas
![](https://cdn.hka.com/wp-content/uploads/2017/10/shutterstock_2101749-1-280x210.jpg)
Port of Long Beach
Americas
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_577717501-280x210.jpeg)
Airport Pavement Management Survey
Americas
![](https://cdn.hka.com/wp-content/uploads/2017/03/pexels-marina-hinic-730778-280x210.jpeg)
Greenfield St George Airport, Utah
Americas
![Kashagan Oilfield Kazakhstan](https://cdn.hka.com/wp-content/uploads/2018/04/Kashagan-280x210.jpg)
A Giant Oilfield
Asia
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_691234552-280x210.jpeg)
Hunter River Remediation
New South Wales, Australia
![](https://cdn.hka.com/wp-content/uploads/2017/03/pexels-pixabay-56832-280x210.jpeg)
Great Western Highway Widening
Victoria, Australia
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_1947842533-280x210.jpeg)
Rail Rehabilitation Scheme
Bucharest to Brasov line, Romania
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_324754607-280x210.jpeg)
Yanbu Power & Desalination Plant
Yanbu Industrial City, Saudi Arabia
Follow HKA on WeChat
关注我们的官方微信公众号
![HKA WeChat](https://cdn.hka.com/wp-content/themes/hka2/assets/img/hka-wechat-qr-code.jpg)