Hunter River Remediation scheme downstream of heavy industry.
The excavation, decontamination and disposal of contaminated river sediment affected by over 70 years of heavy industry on the Hunter River in New South Wales, Australia.
Brief
Retained as delay expert witness.
What we did
Forensic analysis of dredging and onshore treatment of contaminated sediment to establish the actual effect on the critical path of the additional quantities that required treatment.
The progress of dredging, transportation and treatment operations were each analysed to establish to what extent the additional quantities delayed the completion milestones.
The findings were included in an expert delay report.
Outcomes
The parties reached an amicable settlement incorporating an extension of time based on the HKA analysis.
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_691234552-480x340.jpeg)
"Independent forensic analysis can remove the subjectivity and bias that often accompany change on projects.
This type of analysis, with its clear and factual outputs, provides the basis for clients to reach commercial settlements and avoid the considerable cost of arbitration or litigation."
Wendy MacLaughlin
HKA Senior Vice President
-
ClientTheiss
-
Year2012 - 2013
-
ValueUS$ 305.5 million
-
SectorsConstruction and Engineering, Transportation Infrastructure
RELATED PROJECTS
RELATED PROJECTS
![](https://cdn.hka.com/wp-content/uploads/2019/06/pexels-pixabay-162646-280x210.jpeg)
Missouri Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/faris-mohammed-uG5_ERHN040-unsplash-280x210.jpg)
Independent Quantum Expert Opinion of Highway Maintenance Contract
Europe
![](https://cdn.hka.com/wp-content/uploads/2020/10/UNSW5-280x210.jpg)
UNSW Capital Projects Sustainability Framework
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/12/shutterstock_1289920885-280x210.jpeg)
Subsea Cable Installation & Trenching Operations
Asia
![](https://cdn.hka.com/wp-content/uploads/2022/11/shutterstock_191351435-280x210.jpg)
Coal-fired power plant
Asia
![](https://cdn.hka.com/wp-content/uploads/2019/07/pexels-johannes-plenio-4460676-280x210.jpeg)
Spent Nuclear Fuel Verdicts & Settlements
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/matt-seymour-NcmOysOF_Mw-unsplash-280x210.jpg)
Independent Commercial, Cost & Risk Review of Road Development
Europe
![](https://cdn.hka.com/wp-content/uploads/2020/11/yucar-fotografik-cfR-V1QuEKw-unsplash-280x210.jpg)
Sydney Water, Partnering for Success (P4S)
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/12/shutterstock_1372606610-280x210.jpeg)
Subsea Interconnector Cable Failure
Europe
![](https://cdn.hka.com/wp-content/uploads/2022/11/shutterstock_576018130-280x210.jpg)
Coal-fired power plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2019/07/shutterstock_609628034-280x210.jpg)
Longview Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/shutterstock_739242352-280x210.jpeg)
Independent Quantum Expert Review of Maintenance Contract
Europe
![](https://cdn.hka.com/wp-content/uploads/2021/01/AdobeStock_261723143_Melbourne_web-e1707447623872-280x210.jpg)
Melbourne Airport Rail
Oceania
![](https://cdn.hka.com/wp-content/uploads/2022/01/FACD-280x210.jpg)
Energy and Telecom Cable Manufacturer
Americas & Asia
![](https://cdn.hka.com/wp-content/uploads/2022/11/shutterstock_2012903819-280x210.jpg)
Water desalination plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2019/07/pexels-pixabay-263402-280x210.jpeg)
University of North Carolina Hospitals
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/shutterstock_64845340-1-280x210.jpg)
Major Light Rail Transit
Americas
![](https://cdn.hka.com/wp-content/uploads/2021/07/shutterstock_1315203980-3-280x210.jpg)
Liquefied Natural Gas (LNG) Project Australia
Oceania
![](https://cdn.hka.com/wp-content/uploads/2022/07/shutterstock_526595785-280x210.jpeg)
Clean Fuels Project
Middle East
![](https://cdn.hka.com/wp-content/uploads/2021/06/shutterstock_539854030-280x210.jpeg)
Offshore refinery contractor performance review
Asia
![](https://cdn.hka.com/wp-content/uploads/2019/07/shutterstock_1931109776-280x210.jpg)
Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/02/shutterstock_701032348-1-280x210.jpg)
Two New Venues
Middle East
![](https://cdn.hka.com/wp-content/uploads/2021/08/WhatsApp-Image-2021-08-08-at-10.38.13-AM-280x210.jpeg)
Residential Development
Middle East
![](https://cdn.hka.com/wp-content/uploads/2022/07/shutterstock_1700360854-280x210.jpg)
Nuclear Power Plant Decommissioning
Americas
![](https://cdn.hka.com/wp-content/uploads/2023/11/Rozelle-interchange-280x210.jpg)
WestConnex Rozelle Interchange
Oceania
![](https://cdn.hka.com/wp-content/uploads/2019/06/zbynek-burival-517983-unsplash-280x210.jpg)
South American Oil Refinery
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/02/pexels-thirdman-5327915-280x210.jpeg)
A Major Teaching & Research Hospital
Europe
![](https://cdn.hka.com/wp-content/uploads/2021/08/shutterstock_671935024-scaled-1-280x210.jpg)
Natural Gas-Fired Power Plant
Asia
![](https://cdn.hka.com/wp-content/uploads/2022/06/Generic-Industrial-Manufacturing-33-280x210.jpg)
Global chemicals manufacturer
Americas & Europe
![](https://cdn.hka.com/wp-content/uploads/2019/07/shutterstock_137593487-280x210.jpg)
Major Nuclear Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/04/shutterstock_1898870809.jpg)
Nuclear Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2021/06/shutterstock_93575686-280x210.jpeg)
Industrial Manufacturing Facility
Europe
![](https://cdn.hka.com/wp-content/uploads/2022/09/chris-dack-6H9XK16F3wU-unsplash-280x210.jpeg)
Business Park, Surrey
Europe
![](https://cdn.hka.com/wp-content/uploads/2019/08/shutterstock_1112383511-280x210.jpg)
Major Canadian Utility Commercial Damages Matter
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/10/Picture2-280x210.jpg)
New School Campus, Ultimo Primary School
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/12/shutterstock_1085652248-280x210.jpeg)
Subsea Power Cable Failure
Asia
![](https://cdn.hka.com/wp-content/uploads/2022/09/pexels-julia-volk-5201944-280x210.jpeg)
Highway Rock Cuttings
Middle East
![Pioneering Spirit Allseas Oil and Gas Offshore](https://cdn.hka.com/wp-content/uploads/2019/01/allseas-pioneering-spirit-280x210.jpg)
Allseas & Pioneering Spirit
Europe
![Sydney Water Lower South Creek Treatment Program Australia Tap](https://cdn.hka.com/wp-content/uploads/2019/01/bathroom-black-and-white-blur-615326-280x210.jpg)
Lower South Creek Treatment Program
Oceania
![](https://cdn.hka.com/wp-content/uploads/2019/01/pexels-trinity-kubassek-230620-280x210.jpg)
Share our Space Program
Oceania
![Hume Housing | Infrastructure | Expertise | HKA](https://cdn.hka.com/wp-content/uploads/2018/11/Hume-Housing-280x210.png)
Hume Community Housing
Oceania
![](https://cdn.hka.com/wp-content/uploads/2018/09/joey-kyber-Pihl8kTtX-s-unsplash-280x210.jpeg)
Infrastructure Investment Assurance Framework
Oceania
![](https://cdn.hka.com/wp-content/uploads/2018/09/bigstock-Two-electricians-securing-powe-26134499-280x210.jpg)
Electricity Network Improvement
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/06/shutterstock_535814989-280x210.jpg)
High Speed 2 (HS2) Project
Europe
![Sydney Major Transport | Infrastructure | Expertise | HKA](https://cdn.hka.com/wp-content/uploads/2018/10/Sydney-Major-Projects-e1554899277213-280x210.jpeg)
Major Transport Projects Review
Oceania
![City metro Australia Newcastle Project Advisory](https://cdn.hka.com/wp-content/uploads/2018/08/Newcastle_City-Metro-Rail-motion-blur-280x210.jpg)
Urban Transformation & Transport Programme
Oceania
![](https://cdn.hka.com/wp-content/uploads/2018/08/EssentialEnergy-280x210.jpg)
Strategic Procurement & Programme Management Improvement
Oceania
![](https://cdn.hka.com/wp-content/uploads/2017/03/AdobeStock_378243029-280x210.jpeg)
Sydney Metro
Oceania
![Ultimo Pop Up School Australia Sydney](https://cdn.hka.com/wp-content/uploads/2018/07/Ultimo-Pop-Up-School-Australia-280x210.jpg)
Temporary School at Ultimo Primary School
Oceania
![](https://cdn.hka.com/wp-content/uploads/2020/11/Construction-image-scaled-e1635262262716-280x210.jpg)
Gerald Desmond Bridge
Americas
![](https://cdn.hka.com/wp-content/uploads/2021/03/shutterstock_1140608543-280x210.jpg)
Office and Retail Landmark
Americas
![](https://cdn.hka.com/wp-content/uploads/2017/10/shutterstock_2101749-1-280x210.jpg)
Port of Long Beach
Americas
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_577717501-280x210.jpeg)
Airport Pavement Management Survey
Americas
![](https://cdn.hka.com/wp-content/uploads/2017/03/pexels-marina-hinic-730778-280x210.jpeg)
Greenfield St George Airport, Utah
Americas
![Kashagan Oilfield Kazakhstan](https://cdn.hka.com/wp-content/uploads/2018/04/Kashagan-280x210.jpg)
A Giant Oilfield
Asia
![](https://cdn.hka.com/wp-content/uploads/2017/03/pexels-pixabay-56832-280x210.jpeg)
Great Western Highway Widening
Victoria, Australia
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_1947842533-280x210.jpeg)
Rail Rehabilitation Scheme
Bucharest to Brasov line, Romania
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_324754607-280x210.jpeg)
Yanbu Power & Desalination Plant
Yanbu Industrial City, Saudi Arabia
Follow HKA on WeChat
关注我们的官方微信公众号
![HKA WeChat](https://cdn.hka.com/wp-content/themes/hka2/assets/img/hka-wechat-qr-code.jpg)