Brief
Awarded a lump-sum contract, the building services subcontractor was incurring significant unbudgeted costs. Despite delays in completing the design and civil works, the main contractor, who had full design responsibility, had rejected the subcontractor’s claims.
HKA was commissioned to undertake an initial review and prepare a strategy to maximise the commercial position of the MEP subcontractor. We were subsequently appointed to prepare a series of claims for extension of time, delay and disruption related costs and variations.
What we did
HKA assembled a multidisciplinary team, drawing on our QED+ (quantum, engineering, delay) capability.
Our initial review clearly established that failures by the main contractor in its design obligations and allowing access for the MEP works had caused the client critical delays. Significant design changes had also resulted in additional costs.
We advised on the need for more detailed progress updates and daily site records, and devised a strategy that, nevertheless, would provide a strong basis for recovering costs. This included a potential claim for constructive acceleration as well as for design variations, extension of time, and delay and disruption related costs.
In stage two, our team – which comprised five quantum specialists, two engineers and two delay analysts – prepared these claims.
- Variations: A structured workshop with the site team identified time-critical design variations. We reviewed the subcontractor’s previous submissions, carried out our own technical analysis to define the scope of works based on the original design documents, and mapped the extent of the design changes.
Detailed and persuasive claims for each major variation were then prepared. These were extensive, amounting to around a hundred claims.
- Extension of time: Our ‘as-planned versus as-built’ methodology provided the basis for a solid delay analysis backed up with a detailed narrative of logic and findings. When updating the claim, the subsequent period was subjected to a ‘time slice’ retrospective analysis.
We also reviewed the contract to assemble the strongest possible case for the recovery of time and costs arising from each delay event.
- Additional claims: Our team carried out all the necessary assessments to establish entitlement to other costs arising from prolongation, disruption/lost productivity, constructive acceleration (to meet an imposed completion date), and related losses.
The impact of disruption was calculated on an earned value basis. As when updating the EOT claim, with more detailed records available, we could deploy a ‘measured mile’ methodology for the later period. This was then applied retrospectively to supersede the initial claim.
Outcomes
Our integrated QED+ capability was critical both in securing the commission and the subcontractor’s commercial position.
The HKA team safeguarded the rights of our client ahead of arbitration. Our advice on record keeping and subsequent analysis strengthened its claims, which have been prepared to the most rigorous standards possible. Their total value exceeded that of the subcontract.
![](https://cdn.hka.com/wp-content/uploads/2020/02/shutterstock_701032348-1-480x340.jpg)
"Our integrated QED+ capability was critical both in securing the commission and the subcontractor’s commercial position."
-
ClientConfidential
-
Year2018 - 2020
-
ServicesForensic Engineering, Architectural and Technical, Expert, Engineering and Construction Quantum, Delay and Disruption Analysis
-
SectorsConstruction and Engineering, Buildings
RELATED PROJECTS
RELATED PROJECTS
![](https://cdn.hka.com/wp-content/uploads/2019/08/shutterstock_1112383511-280x210.jpg)
Major Canadian Utility Commercial Damages Matter
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/10/UNSW5-280x210.jpg)
UNSW Capital Projects Sustainability Framework
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/12/shutterstock_1289920885-280x210.jpeg)
Subsea Cable Installation & Trenching Operations
Asia
![](https://cdn.hka.com/wp-content/uploads/2022/11/shutterstock_191351435-280x210.jpg)
Coal-fired power plant
Asia
![](https://cdn.hka.com/wp-content/uploads/2019/06/pexels-pixabay-162646-280x210.jpeg)
Missouri Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/faris-mohammed-uG5_ERHN040-unsplash-280x210.jpg)
Independent Quantum Expert Opinion of Highway Maintenance Contract
Europe
![](https://cdn.hka.com/wp-content/uploads/2020/11/yucar-fotografik-cfR-V1QuEKw-unsplash-280x210.jpg)
Sydney Water, Partnering for Success (P4S)
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/12/shutterstock_1372606610-280x210.jpeg)
Subsea Interconnector Cable Failure
Europe
![](https://cdn.hka.com/wp-content/uploads/2022/11/shutterstock_576018130-280x210.jpg)
Coal-fired power plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2019/07/pexels-johannes-plenio-4460676-280x210.jpeg)
Spent Nuclear Fuel Verdicts & Settlements
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/matt-seymour-NcmOysOF_Mw-unsplash-280x210.jpg)
Independent Commercial, Cost & Risk Review of Road Development
Europe
![](https://cdn.hka.com/wp-content/uploads/2021/01/AdobeStock_261723143_Melbourne_web-e1707447623872-280x210.jpg)
Melbourne Airport Rail
Oceania
![](https://cdn.hka.com/wp-content/uploads/2022/01/FACD-280x210.jpg)
Energy and Telecom Cable Manufacturer
Americas & Asia
![](https://cdn.hka.com/wp-content/uploads/2022/11/shutterstock_2012903819-280x210.jpg)
Water desalination plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2019/07/shutterstock_609628034-280x210.jpg)
Longview Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/shutterstock_739242352-280x210.jpeg)
Independent Quantum Expert Review of Maintenance Contract
Europe
![](https://cdn.hka.com/wp-content/uploads/2021/07/shutterstock_1315203980-3-280x210.jpg)
Liquefied Natural Gas (LNG) Project Australia
Oceania
![](https://cdn.hka.com/wp-content/uploads/2022/07/shutterstock_526595785-280x210.jpeg)
Clean Fuels Project
Middle East
![](https://cdn.hka.com/wp-content/uploads/2021/06/shutterstock_539854030-280x210.jpeg)
Offshore refinery contractor performance review
Asia
![](https://cdn.hka.com/wp-content/uploads/2019/07/pexels-pixabay-263402-280x210.jpeg)
University of North Carolina Hospitals
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/01/shutterstock_64845340-1-280x210.jpg)
Major Light Rail Transit
Americas
![](https://cdn.hka.com/wp-content/uploads/2021/08/WhatsApp-Image-2021-08-08-at-10.38.13-AM-280x210.jpeg)
Residential Development
Middle East
![](https://cdn.hka.com/wp-content/uploads/2022/07/shutterstock_1700360854-280x210.jpg)
Nuclear Power Plant Decommissioning
Americas
![](https://cdn.hka.com/wp-content/uploads/2023/11/Rozelle-interchange-280x210.jpg)
WestConnex Rozelle Interchange
Oceania
![](https://cdn.hka.com/wp-content/uploads/2019/07/shutterstock_1931109776-280x210.jpg)
Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/02/pexels-thirdman-5327915-280x210.jpeg)
A Major Teaching & Research Hospital
Europe
![](https://cdn.hka.com/wp-content/uploads/2021/08/shutterstock_671935024-scaled-1-280x210.jpg)
Natural Gas-Fired Power Plant
Asia
![](https://cdn.hka.com/wp-content/uploads/2022/06/Generic-Industrial-Manufacturing-33-280x210.jpg)
Global chemicals manufacturer
Americas & Europe
![](https://cdn.hka.com/wp-content/uploads/2019/06/zbynek-burival-517983-unsplash-280x210.jpg)
South American Oil Refinery
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/04/shutterstock_1898870809.jpg)
Nuclear Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2021/06/shutterstock_93575686-280x210.jpeg)
Industrial Manufacturing Facility
Europe
![](https://cdn.hka.com/wp-content/uploads/2022/09/chris-dack-6H9XK16F3wU-unsplash-280x210.jpeg)
Business Park, Surrey
Europe
![](https://cdn.hka.com/wp-content/uploads/2019/07/shutterstock_137593487-280x210.jpg)
Major Nuclear Power Plant
Americas
![](https://cdn.hka.com/wp-content/uploads/2020/10/Picture2-280x210.jpg)
New School Campus, Ultimo Primary School
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/12/shutterstock_1085652248-280x210.jpeg)
Subsea Power Cable Failure
Asia
![](https://cdn.hka.com/wp-content/uploads/2022/09/pexels-julia-volk-5201944-280x210.jpeg)
Highway Rock Cuttings
Middle East
![](https://cdn.hka.com/wp-content/uploads/2019/01/pexels-trinity-kubassek-230620-280x210.jpg)
Share our Space Program
Oceania
![Pioneering Spirit Allseas Oil and Gas Offshore](https://cdn.hka.com/wp-content/uploads/2019/01/allseas-pioneering-spirit-280x210.jpg)
Allseas & Pioneering Spirit
Europe
![Sydney Water Lower South Creek Treatment Program Australia Tap](https://cdn.hka.com/wp-content/uploads/2019/01/bathroom-black-and-white-blur-615326-280x210.jpg)
Lower South Creek Treatment Program
Oceania
![Hume Housing | Infrastructure | Expertise | HKA](https://cdn.hka.com/wp-content/uploads/2018/11/Hume-Housing-280x210.png)
Hume Community Housing
Oceania
![](https://cdn.hka.com/wp-content/uploads/2018/09/joey-kyber-Pihl8kTtX-s-unsplash-280x210.jpeg)
Infrastructure Investment Assurance Framework
Oceania
![](https://cdn.hka.com/wp-content/uploads/2018/09/bigstock-Two-electricians-securing-powe-26134499-280x210.jpg)
Electricity Network Improvement
Oceania
![](https://cdn.hka.com/wp-content/uploads/2021/06/shutterstock_535814989-280x210.jpg)
High Speed 2 (HS2) Project
Europe
![Sydney Major Transport | Infrastructure | Expertise | HKA](https://cdn.hka.com/wp-content/uploads/2018/10/Sydney-Major-Projects-e1554899277213-280x210.jpeg)
Major Transport Projects Review
Oceania
![City metro Australia Newcastle Project Advisory](https://cdn.hka.com/wp-content/uploads/2018/08/Newcastle_City-Metro-Rail-motion-blur-280x210.jpg)
Urban Transformation & Transport Programme
Oceania
![](https://cdn.hka.com/wp-content/uploads/2018/08/EssentialEnergy-280x210.jpg)
Strategic Procurement & Programme Management Improvement
Oceania
![](https://cdn.hka.com/wp-content/uploads/2017/03/AdobeStock_378243029-280x210.jpeg)
Sydney Metro
Oceania
![Ultimo Pop Up School Australia Sydney](https://cdn.hka.com/wp-content/uploads/2018/07/Ultimo-Pop-Up-School-Australia-280x210.jpg)
Temporary School at Ultimo Primary School
Oceania
![](https://cdn.hka.com/wp-content/uploads/2020/11/Construction-image-scaled-e1635262262716-280x210.jpg)
Gerald Desmond Bridge
Americas
![](https://cdn.hka.com/wp-content/uploads/2021/03/shutterstock_1140608543-280x210.jpg)
Office and Retail Landmark
Americas
![](https://cdn.hka.com/wp-content/uploads/2017/10/shutterstock_2101749-1-280x210.jpg)
Port of Long Beach
Americas
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_577717501-280x210.jpeg)
Airport Pavement Management Survey
Americas
![](https://cdn.hka.com/wp-content/uploads/2017/03/pexels-marina-hinic-730778-280x210.jpeg)
Greenfield St George Airport, Utah
Americas
![Kashagan Oilfield Kazakhstan](https://cdn.hka.com/wp-content/uploads/2018/04/Kashagan-280x210.jpg)
A Giant Oilfield
Asia
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_691234552-280x210.jpeg)
Hunter River Remediation
New South Wales, Australia
![](https://cdn.hka.com/wp-content/uploads/2017/03/pexels-pixabay-56832-280x210.jpeg)
Great Western Highway Widening
Victoria, Australia
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_1947842533-280x210.jpeg)
Rail Rehabilitation Scheme
Bucharest to Brasov line, Romania
![](https://cdn.hka.com/wp-content/uploads/2017/03/shutterstock_324754607-280x210.jpeg)
Yanbu Power & Desalination Plant
Yanbu Industrial City, Saudi Arabia
Follow HKA on WeChat
关注我们的官方微信公众号
![HKA WeChat](https://cdn.hka.com/wp-content/themes/hka2/assets/img/hka-wechat-qr-code.jpg)